I85PREP
⌘ K
NE General Contractor study materials
NE General Contractor study resources

NE General Contractor practice questions

One question at a time. Build your NE General Contractor understanding.

First 50 of 200 questions. Each one lists the choices, the correct answer, and an explanation. The checker at the top of this page saves progress in this browser when it is available.

Continue in the practice tool above to load more questions, 50 at a time.

Question 1Business Organization, Licensing, and Nebraska Law

Under Nebraska law, a general contractor who performs work on a project in Nebraska without holding the required state contractor license is exposed to which of the following consequences?

  1. The contractor's liability insurance policy is voided by operation of law.
  2. The contractor may continue only if the owner signs a written waiver of licensing.
  3. The contractor is automatically granted a provisional license retroactive to the start date.
  4. The contractor may face civil penalties and lose the ability to enforce the contract in court. Correct answer.

Explanation

Nebraska requires contractors to be licensed, and unlicensed contracting exposes the contractor to civil penalties and can bar recovery in a contract action. An owner's private waiver does not cure the statutory licensing requirement, and no provisional license is created automatically.

Question 2Business Organization, Licensing, and Nebraska Law

Which Nebraska entity is responsible for issuing licenses to contractors at the state level?

  1. The Nebraska Department of Insurance
  2. The Nebraska Real Estate Commission
  3. The Nebraska Department of Environment and Energy
  4. The Nebraska Department of Labor Correct answer.

Explanation

Contractor licensing in Nebraska is administered through the Department of Labor, which handles applications, renewals, and enforcement. The other listed agencies regulate real estate, insurance, and environmental matters, not contractor licensing.

Question 3Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is forming a limited liability company to limit personal liability. Which characteristic is most closely associated with an LLC as a business form?

  1. Members are personally liable for all company debts as in a general partnership.
  2. Owners, called members, generally are not personally liable for company obligations. Correct answer.
  3. The entity must have at least two owners to be recognized in Nebraska.
  4. Ownership interests are freely transferable without any restriction.

Explanation

An LLC shields its members from personal liability for the entity's debts and obligations, similar to a corporation. Nebraska allows single-member LLCs, and transfer restrictions are typically governed by the operating agreement.

Question 4Business Organization, Licensing, and Nebraska Law

In Nebraska, a partnership in which all partners share management and have unlimited personal liability for partnership debts is best described as which of the following?

  1. A sole proprietorship
  2. A limited partnership
  3. A limited liability partnership
  4. A general partnership Correct answer.

Explanation

A general partnership involves shared management and joint and several liability for all partners. Limited partnerships include limited partners with reduced liability, and LLPs provide liability shields that a plain general partnership does not.

Question 5Business Organization, Licensing, and Nebraska Law

A Nebraska contractor signs a contract that includes a clause requiring all disputes to be resolved through binding arbitration. Which statement about this clause is correct?

  1. Arbitration awards may be appealed on the merits as a matter of right.
  2. Only a court may decide whether the arbitration clause applies.
  3. A valid arbitration agreement is generally enforceable and limits resort to litigation. Correct answer.
  4. Arbitration clauses are unenforceable in construction contracts in Nebraska.

Explanation

Nebraska recognizes arbitration agreements, and a valid clause generally requires parties to arbitrate rather than litigate. Judicial review of arbitration awards is narrow and does not allow a full appeal on the merits.

Question 6Business Organization, Licensing, and Nebraska Law

Which of the following is a typical requirement for obtaining a Nebraska contractor license?

  1. Submitting proof of a surety bond or financial responsibility Correct answer.
  2. Holding a real estate broker license
  3. Maintaining a physical office in every county where work is performed
  4. Joining a statewide trade association

Explanation

Nebraska licensing typically requires demonstrating financial responsibility, often through a surety bond or equivalent. County offices, broker licenses, and trade association membership are not general prerequisites.

Question 7Business Organization, Licensing, and Nebraska Law

A Nebraska contractor wants to protect a distinctive business name used in advertising. Which step best establishes exclusive rights to the name under state law?

  1. Recording the name with the county clerk
  2. Obtaining a federal tax identification number
  3. Registering the name as a trade name with the appropriate state office Correct answer.
  4. Publishing the name in a local newspaper

Explanation

Registering a trade name with the state provides notice and helps establish exclusive rights to the name. Newspaper publication, county recording, and an EIN do not by themselves create exclusive name rights.

Question 8Business Organization, Licensing, and Nebraska Law

Under Nebraska's mechanics' lien law, which party is generally entitled to file a lien against a construction project?

  1. The project lender
  2. A prospective buyer who toured the site
  3. A neighboring property owner
  4. A material supplier who furnished materials to the project Correct answer.

Explanation

Mechanics' lien statutes protect parties who furnish labor or materials to improve real property, including material suppliers. Neighbors, lenders, and prospective buyers have not contributed labor or materials and generally cannot claim a lien.

Question 9Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is preparing to bid on a public project. Which statement best describes the typical requirement for bid bonds on public construction contracts?

  1. Bid bonds replace the need for a performance bond.
  2. Bid bonds are never required on public projects.
  3. Bid bonds are required only when the project exceeds one million dollars.
  4. Bid bonds are commonly required to guarantee that the bidder will enter the contract if awarded. Correct answer.

Explanation

A bid bond assures the owner that the successful bidder will execute the contract and furnish required bonds. It does not eliminate the need for a performance bond, and dollar thresholds vary by project rather than being fixed at one million dollars.

Question 10Business Organization, Licensing, and Nebraska Law

A subcontractor on a Nebraska project has not been paid by the general contractor. Which remedy is most directly available under mechanics' lien law?

  1. Filing a lien against the property within the statutory time period Correct answer.
  2. Requesting the state to suspend the general contractor's license automatically
  3. Recording a lis pendens against the owner's personal residence
  4. Filing a criminal complaint for theft

Explanation

An unpaid subcontractor may assert a mechanics' lien against the improved property, provided statutory notice and timing requirements are met. License suspension and criminal charges are not automatic remedies for nonpayment, and a lis pendens on an unrelated residence is improper.

Question 11Business Organization, Licensing, and Nebraska Law

A Nebraska contractor operates as a sole proprietorship. Which statement accurately describes the owner's liability?

  1. The owner is liable only for obligations exceeding the business's assets.
  2. The owner's liability is capped at the amount of business insurance carried.
  3. The owner is personally liable for business obligations without limit. Correct answer.
  4. The owner has no personal liability for business debts.

Explanation

A sole proprietorship is not a separate legal entity, so the owner bears unlimited personal liability for business debts and claims. Insurance may cover some losses but does not cap legal liability.

Question 12Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is reviewing a contract that contains an indemnification clause requiring the contractor to hold the owner harmless for the owner's own negligence. How should the contractor treat this clause?

  1. Treat it as automatically converting the contract into a joint venture.
  2. Ignore it because indemnity clauses apply only to design professionals.
  3. Recognize that such clauses are generally enforceable but may be limited by statute or public policy. Correct answer.
  4. Assume it is unenforceable because indemnity clauses are void in Nebraska.

Explanation

Indemnification provisions are generally enforceable in Nebraska, though statutes and public policy can limit attempts to shift responsibility for another party's negligence. They do not create a joint venture or apply only to designers.

Question 13Business Organization, Licensing, and Nebraska Law

A Nebraska contractor discovers that a competitor is using a confusingly similar business name. Which legal theory most directly supports a claim to stop the competitor?

  1. Negligent misrepresentation
  2. Unfair competition and trademark infringement Correct answer.
  3. Strict product liability
  4. Breach of the implied warranty of habitability

Explanation

Unfair competition and trademark law protect against use of a confusingly similar name that diverts customers. The other theories concern defective work, product defects, or false statements, not name confusion.

Question 14Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is asked to sign a contract that includes a clause requiring all disputes to be litigated in a distant state. Which consideration is most relevant to whether the clause will be enforced?

  1. Whether the contractor belongs to a trade association
  2. Whether the contract was notarized
  3. Whether the chosen forum has a reasonable relationship to the parties or the transaction Correct answer.
  4. Whether the contractor has a state contractor license

Explanation

Forum-selection clauses are generally enforced when the chosen forum is reasonable and not fundamentally unfair, often assessed by the forum's relationship to the parties or transaction. Licensing, notarization, and association membership do not determine enforceability.

Question 15Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is bidding on a project and wants to withdraw a bid after the bid opening but before award. Which factor is most important in determining whether withdrawal is permitted?

  1. Whether the bidder has a surety bond
  2. Whether the bid was submitted electronically
  3. Whether the owner has already signed a contract with another bidder
  4. Whether the bidder can show a material mistake or other recognized ground for relief Correct answer.

Explanation

After bid opening, withdrawal is generally allowed only for recognized grounds such as a material mistake, and the bid bond may be forfeited otherwise. Electronic submission, other bidders' status, and bonding do not by themselves authorize withdrawal.

Question 16Business Organization, Licensing, and Nebraska Law

A Nebraska contractor has an employee who is injured on the job. Which statement best describes the contractor's obligation under Nebraska workers' compensation law?

  1. The employer must provide workers' compensation coverage for covered employees. Correct answer.
  2. Coverage is optional for all construction employers.
  3. The employee must purchase individual coverage before starting work.
  4. Coverage is required only for employees earning above a wage threshold.

Explanation

Nebraska requires employers meeting statutory thresholds to carry workers' compensation coverage for their employees. Coverage is not optional, wage-based, or the employee's personal responsibility.

Question 17Business Organization, Licensing, and Nebraska Law

A Nebraska contractor hires a worker as an independent contractor rather than an employee. Which factor is most relevant to whether that classification will be respected?

  1. The contractor's annual revenue
  2. The label used in the written agreement alone
  3. The degree of control the contractor exercises over the worker's work Correct answer.
  4. The worker's age

Explanation

Worker classification turns primarily on the degree of control and independence in performing the work, not merely on labels in a contract. Age and revenue are not the controlling factors.

Question 18Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is required to provide a performance bond on a public project. What does a performance bond primarily guarantee?

  1. That the contractor will complete the work according to the contract terms Correct answer.
  2. That material prices will remain stable
  3. That the contractor will obtain all required permits
  4. That the owner will pay the contractor on time

Explanation

A performance bond assures the owner that the contractor will fulfill the contract and complete the work. Payment timing, permitting, and price stability are not the purpose of a performance bond.

Question 19Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is incorporated. Which document typically establishes the corporation and authorizes it to do business?

  1. The articles of incorporation Correct answer.
  2. The operating agreement
  3. The bylaws amendment
  4. The partnership certificate

Explanation

Articles of incorporation are filed with the state to create a corporation, while bylaws govern internal operations. Operating agreements apply to LLCs, and partnership certificates apply to partnerships.

Question 20Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is reviewing a contract that requires written change orders for all extra work. A verbal directive from the owner's representative orders additional work. What is the contractor's best course of action to preserve payment?

  1. Proceed and rely on the verbal directive as sufficient authorization
  2. Obtain a written change order or written confirmation before or promptly after performing the work Correct answer.
  3. Wait until final payment to raise the issue
  4. Refuse to perform any additional work under any circumstances

Explanation

When a contract requires written change orders, the contractor should document the directive in writing to preserve a claim for payment. Relying on a verbal order risks nonpayment, and refusing all extra work may itself breach the contract.

Question 21Business Organization, Licensing, and Nebraska Law

A Nebraska contractor has completed work but the owner refuses to pay, claiming the work is defective. Which step is most important for the contractor to protect its mechanics' lien rights?

  1. Waiting until the dispute is resolved before taking any action
  2. Recording a lien within the statutory deadline and serving required notices Correct answer.
  3. Filing a police report against the owner
  4. Publishing a notice in a trade magazine

Explanation

Mechanics' lien rights are time-sensitive; the contractor must record the lien and serve required notices within statutory deadlines. Waiting for the dispute to resolve may cause the lien right to lapse.

Question 22Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is forming a limited partnership to develop property. Which statement correctly describes the liability of a limited partner?

  1. A limited partner has unlimited personal liability for partnership debts.
  2. A limited partner must manage the partnership's daily operations.
  3. A limited partner's liability is generally limited to the partner's investment. Correct answer.
  4. A limited partner cannot contribute capital.

Explanation

Limited partners generally risk only their invested capital and do not participate in management. General partners bear unlimited liability, and limited partners may contribute capital.

Question 23Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is evaluating whether a clause shifting all risk of site conditions to the contractor is enforceable. Which principle is most relevant?

  1. Courts may enforce risk-shifting clauses unless they are unconscionable or barred by statute. Correct answer.
  2. Risk-shifting clauses apply only to public projects.
  3. Risk-shifting clauses require approval by the contractor's surety.
  4. Such clauses are always void as against public policy.

Explanation

Risk-allocation clauses are generally enforced between sophisticated parties unless they are unconscionable, ambiguous, or prohibited by statute. They are not limited to public work and do not require surety approval.

Question 24Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is accused of bid-rigging on a public project. Which area of law is most directly implicated?

  1. Zoning law
  2. Workers' compensation law
  3. Mechanics' lien law
  4. Antitrust and unfair trade practices law Correct answer.

Explanation

Bid-rigging is a form of anticompetitive conduct addressed by antitrust and unfair trade practices law. Mechanics' liens, workers' compensation, and zoning concern payment rights, employee injuries, and land use respectively.

Question 25Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is negotiating an owner-drafted contract that includes a broad no-damages-for-delay clause. Which analysis best reflects how such a clause is generally treated?

  1. It applies only to subcontractors.
  2. It is unenforceable in all circumstances.
  3. It is generally enforceable but may be limited by exceptions such as owner bad faith or unreasonable delay. Correct answer.
  4. It automatically shifts responsibility to the design professional.

Explanation

No-damages-for-delay clauses are typically enforceable, but courts may recognize exceptions for bad faith, active interference, or delays outside the clause's scope. They do not apply only to subcontractors or shift liability to designers.

Question 26Business Organization, Licensing, and Nebraska Law

A Nebraska contractor who performs residential work wants to use a contract that includes a clause allowing the contractor to keep all deposits if the homeowner cancels for any reason. Which Nebraska legal principle most directly limits the enforceability of that clause?

  1. The doctrine that unconscionable contract terms may be refused enforcement Correct answer.
  2. The rule that all construction contracts must be recorded with the county
  3. The statute that voids any contract lacking a written arbitration clause
  4. The requirement that deposits be held in an interest-bearing escrow account

Explanation

Nebraska courts may decline to enforce contract provisions deemed unconscionable, meaning terms so one-sided or oppressive that no reasonable person would accept them. A clause letting a contractor retain all deposits regardless of cause is the kind of overreaching term a court could strike or limit. The other choices describe requirements that Nebraska law does not impose on residential construction contracts generally.

Question 27Business Organization, Licensing, and Nebraska Law

A Nebraska contractor organized as an LLC is applying for a license and must show the business entity is in good standing. Which filing most directly demonstrates that the LLC remains authorized to transact business in Nebraska?

  1. A federal employer identification number confirmation letter
  2. A current biennial report filed with the Nebraska Secretary of State Correct answer.
  3. A surety bond certificate filed with the city clerk
  4. A recorded mechanics' lien release

Explanation

Nebraska limited liability companies maintain good standing by filing periodic reports with the Secretary of State and paying the associated fees. A current biennial report shows the entity has kept its registration active. Lien releases, bonds, and EIN letters serve unrelated purposes and do not establish state registration status.

Question 28Business Organization, Licensing, and Nebraska Law

A Nebraska general contractor signs a contract with an owner that names the contractor as an additional insured on the owner's liability policy for claims arising from the contractor's own negligence. During the project, an owner employee is injured by the contractor's operations. How does the additional insured status most likely affect the contractor's exposure?

  1. It bars the injured employee from filing a workers' compensation claim
  2. It eliminates the contractor's liability because the owner's policy becomes primary for all claims
  3. It transfers the contractor's defense to the owner personally rather than to the insurer
  4. It provides insurance coverage for the contractor's covered liability, subject to the policy's terms and limits Correct answer.

Explanation

Additional insured status extends the owner's policy to cover the contractor for liability arising out of the contractor's covered operations, but only within the policy's terms, exclusions, and limits. It does not erase the contractor's underlying liability or shift the duty to defend onto the owner personally. Workers' compensation rights are governed separately and are unaffected by insurance endorsements.

Question 29Business Organization, Licensing, and Nebraska Law

A Nebraska contractor is deciding whether to organize as a corporation or as a general partnership. Which consequence most accurately distinguishes the corporation from the general partnership for liability purposes?

  1. General partners enjoy limited liability, while corporate shareholders face unlimited liability
  2. Corporate shareholders are personally liable for corporate debts, while general partners are not
  3. Corporate shareholders generally are shielded from business debts, while general partners face personal liability Correct answer.
  4. Both forms shield owners equally, so the choice has no liability effect

Explanation

A corporation is a separate legal entity, so its shareholders ordinarily are not personally responsible for corporate obligations. A general partnership does not provide that shield, and each general partner can be personally liable for partnership debts. The distinction matters when a contractor chooses a business form to manage risk.

Question 30Business Organization, Licensing, and Nebraska Law

A Nebraska contractor's license renewal is due, and the contractor has an unpaid final judgment from a prior construction defect case. Which statement best describes the likely effect of that judgment on the contractor's ability to maintain licensure?

  1. The judgment has no bearing because licensing addresses only technical competence
  2. The judgment converts the license into a probationary permit until the debt is paid in full
  3. The judgment may support disciplinary action or denial of renewal if it reflects unfitness or failure to satisfy obligations Correct answer.
  4. The judgment automatically voids all prior contracts the contractor completed

Explanation

Nebraska licensing authorities may consider conduct such as unsatisfied judgments or failure to meet legal obligations when deciding whether an applicant or licensee is fit to hold a license. The effect is discretionary review and possible discipline, not automatic. Licensing is not limited to technical skill, and a judgment does not retroactively void completed contracts.

Question 31Contract Administration, Bidding, and Project Management

Under Nebraska's Contractor's Bond requirement, when must a general contractor furnish a payment bond on a public improvement project?

  1. Only when the contract exceeds $100,000
  2. Whenever the contract exceeds $15,000 Correct answer.
  3. Only when subcontractors request one in writing
  4. Only on federally funded projects

Explanation

Nebraska law requires a contractor's bond (payment and performance) on public improvement contracts exceeding $15,000, protecting the public body and subcontractors. The threshold is statutory and applies regardless of funding source.

Question 32Contract Administration, Bidding, and Project Management

A general contractor submits a bid to a Nebraska public body and later discovers a clerical error in the bid. Which action is most consistent with standard bid-error relief practice?

  1. Withdraw the bid after award without consequence
  2. Refuse to sign the contract and demand re-bidding
  3. Seek relief before award by providing clear and convincing evidence of the mistake Correct answer.
  4. Submit a revised bid after the bid opening

Explanation

Bid-error relief generally requires the bidder to notify the owner promptly and prove the mistake by clear and convincing evidence before the award. After award, relief is much harder to obtain and withdrawal can trigger bid bond liability.

Question 33Contract Administration, Bidding, and Project Management

On a Nebraska public project, a subcontractor's bid is incorporated into the general contractor's bid. In the absence of a formal subcontract, what doctrine may bind the general contractor to the subcontractor's price?

  1. Res ipsa loquitur
  2. Quantum meruit
  3. Eminent domain
  4. Promissory estoppel Correct answer.

Explanation

Promissory estoppel can bind a general contractor to a subcontractor's bid when the sub reasonably relied on the general's request to use its price and the general used that price in its own bid. This protects the reliance interest created during bid shopping.

Question 34Contract Administration, Bidding, and Project Management

Which document typically establishes the order of precedence among contract documents on a Nebraska construction project?

  1. The contractor's bid form
  2. The building permit
  3. The agreement and general conditions Correct answer.
  4. The subcontractor's proposal letter

Explanation

The agreement and general conditions usually contain the order-of-precedence clause that resolves conflicts among drawings, specifications, and other documents. This clause is essential when documents are inconsistent.

Question 35Contract Administration, Bidding, and Project Management

A Nebraska owner wants to use the design-bid-build delivery method. Which sequence correctly describes the typical project phases?

  1. Bid, design, construct, award
  2. Design, construct, bid, award
  3. Construct, design, bid, award
  4. Design, bid, award, construct Correct answer.

Explanation

Design-bid-build proceeds with the owner hiring a designer, completing design, soliciting competitive bids, awarding to the low responsible bidder, and then constructing. This linear sequence separates design from construction.

Question 36Contract Administration, Bidding, and Project Management

A general contractor on a Nebraska project wants to substitute a specified product with an equal product. What must the contractor typically submit, and when?

  1. A lien waiver
  2. A verbal request to the superintendent
  3. A change order after installation
  4. A substitution request with supporting data before the bid or within the specified period Correct answer.

Explanation

Substitution requests generally require written documentation demonstrating equivalency and must be submitted within the time stated in the specifications, often before bid or early in the project. Late substitutions can be rejected.

Question 37Contract Administration, Bidding, and Project Management

In Nebraska, which lien right generally applies to a general contractor who has not been paid for work on a private project?

  1. Easement by prescription
  2. Zoning variance
  3. Mechanic's lien Correct answer.
  4. Quiet title action

Explanation

A mechanic's lien allows a contractor who furnished labor or materials to encumber the improved property until paid. Nebraska requires strict compliance with statutory notice and filing deadlines.

Question 38Contract Administration, Bidding, and Project Management

A Nebraska general contractor receives a notice of a subcontractor's intent to file a lien. What is the contractor's best immediate step to protect the owner and itself?

  1. Verify payment status and coordinate with the owner and surety Correct answer.
  2. Immediately terminate the subcontract
  3. Record a lis pendens against the subcontractor
  4. Ignore it until the lien is filed

Explanation

Upon notice of a potential lien, the contractor should verify whether the sub has been paid, address any legitimate claim, and notify the owner and surety. Prompt resolution prevents lien filing and project disruption.

Question 39Contract Administration, Bidding, and Project Management

Which type of construction contract places the greatest cost risk on the general contractor?

  1. Time and materials with a cap
  2. Cost-plus-fee
  3. Lump-sum Correct answer.
  4. Unit-price

Explanation

A lump-sum contract fixes the price, so the contractor bears the risk of cost overruns. Cost-plus and unit-price arrangements shift more risk to the owner or allocate by quantity.

Question 40Contract Administration, Bidding, and Project Management

A Nebraska project owner issues a change order reducing the scope of work. The contractor has already mobilized. What is the contractor's most appropriate claim?

  1. Liquidated damages against the owner
  2. Breach of warranty
  3. Mechanic's lien for unperformed work
  4. Equitable adjustment for reduced scope impacts Correct answer.

Explanation

A deductive change that disrupts mobilization or creates inefficiency may entitle the contractor to an equitable adjustment for impact costs. The contractor must document the causal effect of the reduction.

Question 41Contract Administration, Bidding, and Project Management

Which scheduling method is most commonly required for Nebraska public construction projects to demonstrate delay and sequence?

  1. Bar chart
  2. Gantt-only schedule
  3. Critical path method Correct answer.
  4. Line of balance

Explanation

The critical path method identifies activities that control project duration and is standard for analyzing delay and sequencing on public work. It supports time-impact analysis for claims.

Question 42Contract Administration, Bidding, and Project Management

A contractor on a Nebraska project experiences a delay caused by the owner's failure to provide site access. Which type of delay is this generally classified as?

  1. Non-excusable
  2. Compensable Correct answer.
  3. Excusable non-compensable
  4. Concurrent

Explanation

Owner-caused delay that affects the critical path is generally compensable, entitling the contractor to time and money. Documentation of the causal link and costs is required.

Question 43Contract Administration, Bidding, and Project Management

In Nebraska, what is the typical purpose of a bid bond submitted with a public project bid?

  1. Ensure the bidder will enter the contract and furnish required bonds Correct answer.
  2. Pay subcontractors directly
  3. Guarantee the contractor's warranty obligations
  4. Secure building permits

Explanation

A bid bond assures the owner that the low bidder will execute the contract and provide performance and payment bonds. If the bidder fails, the surety may be liable up to the bond penalty.

Question 44Contract Administration, Bidding, and Project Management

A general contractor is preparing a bid for a Nebraska school district project. Which cost item is most often a significant risk if omitted from the bid estimate?

  1. Nebraska sales tax on materials Correct answer.
  2. Owner's financing costs
  3. The architect's design fee
  4. The owner's contingency

Explanation

Contractors must account for applicable Nebraska sales and use tax on materials in their bids; omitting it can erode profit. Owner financing, design fees, and owner contingency are not contractor bid costs.

Question 45Contract Administration, Bidding, and Project Management

Which contract clause typically allows the owner to suspend work and later adjust the contract time and price?

  1. Severability clause
  2. Suspension of work clause Correct answer.
  3. Indemnification clause
  4. Assignment clause

Explanation

A suspension of work clause authorizes the owner to stop work and provides for equitable adjustment of time and cost when the suspension is not the contractor's fault. It is distinct from termination provisions.

Question 46Contract Administration, Bidding, and Project Management

A Nebraska contractor discovers a differing site condition not shown in the geotechnical report. What action best preserves the contractor's claim?

  1. Submit a lien against the owner's property
  2. Proceed without notice and claim at project closeout
  3. Give prompt written notice and document the condition before disturbing it Correct answer.
  4. Refuse to perform until the owner pays

Explanation

Differing site condition clauses generally require prompt written notice and documentation before the condition is altered. Failure to give timely notice can waive the claim.

Question 47Contract Administration, Bidding, and Project Management

Which statement best describes the purpose of a Nebraska pre-bid conference?

  1. To negotiate subcontractor prices
  2. To finalize change orders
  3. To clarify project requirements and allow questions before bidding Correct answer.
  4. To award the contract to the low bidder

Explanation

A pre-bid conference lets the owner and designer clarify scope, site conditions, and bidding requirements so all bidders have consistent information. It does not award or negotiate the contract.

Question 48Contract Administration, Bidding, and Project Management

A general contractor on a Nebraska project fails to meet a contractual milestone. The owner assesses liquidated damages. What must the owner generally show to enforce the clause?

  1. That the delay was concurrent
  2. Actual damages exceeding the stipulated amount
  3. That the amount is a reasonable forecast of anticipated harm Correct answer.
  4. That the contractor acted in bad faith

Explanation

Liquidated damages are enforceable when the amount is a reasonable forecast of anticipated loss at contract formation and actual damages are difficult to estimate. The owner need not prove actual damages.

Question 49Contract Administration, Bidding, and Project Management

Which party typically issues a certificate of substantial completion on a Nebraska construction project?

  1. The surety
  2. The subcontractor
  3. The architect or engineer of record Correct answer.
  4. The general contractor alone

Explanation

The design professional of record generally certifies substantial completion based on inspection and the contract documents. This certification triggers warranty periods and release of retainage in many contracts.

Question 50Contract Administration, Bidding, and Project Management

In Nebraska, retainage on a public improvement contract is generally limited to what percentage of each progress payment unless otherwise provided?

  1. 5 percent Correct answer.
  2. 10 percent
  3. 15 percent
  4. 20 percent

Explanation

Nebraska statutes generally cap retainage on public improvement contracts at 5 percent of each progress payment. Higher retainage may be negotiated on private work but public limits protect contractors.