I85PREP
⌘ K
OK General Contractor study materials
OK General Contractor study resources

OK General Contractor practice questions

One question at a time. Build your OK General Contractor understanding.

First 50 of 200 questions. Each one lists the choices, the correct answer, and an explanation. The checker at the top of this page saves progress in this browser when it is available.

Continue in the practice tool above to load more questions, 50 at a time.

Question 1Business and Project Management

Under a standard lump-sum construction contract, what does the contractor generally assume by agreeing to a fixed price?

  1. A guaranteed profit margin set by the owner at bid opening
  2. The risk of most cost overruns unless the contract provides for a price adjustment Correct answer.
  3. No responsibility for site conditions discovered after signing
  4. That the owner will cover any labor rate increases during the project

Explanation

A lump-sum or stipulated-sum contract transfers substantial cost risk to the contractor, who commits to a price before work begins. The contractor absorbs overruns unless the contract includes an adjustment clause, such as for changed conditions or owner-directed changes. This risk allocation is the defining commercial feature of lump-sum pricing.

Question 2Business and Project Management

A project owner wants to begin construction before the design is fully complete. Which delivery method is designed to overlap design and construction phases?

  1. Design-build Correct answer.
  2. Design-bid-build
  3. Job order contracting
  4. Construction management at risk

Explanation

Design-build combines design and construction under one contract, allowing the builder to start early packages while design continues. This fast-track overlap is the method's central advantage. Design-bid-build is strictly sequential, which makes it unsuitable for overlapping phases.

Question 3Business and Project Management

In a typical construction schedule, what does the critical path represent?

  1. The list of tasks assigned to the general contractor's own forces
  2. The activities that can be delayed without affecting the finish date
  3. The longest path through the network, which sets the minimum project duration Correct answer.
  4. The sequence of activities with the largest budget allocation

Explanation

The critical path is the longest duration path through the activity network, and its length determines the earliest possible project completion. Activities on that path have zero total float, so any delay there delays the project. Float, by contrast, belongs to non-critical activities.

Question 4Business and Project Management

What is the primary purpose of a contractor's safety program on a construction site?

  1. To satisfy the owner's insurance carrier only
  2. To reduce the number of inspections required by regulators
  3. To prevent worker injuries and control losses through hazard identification and training Correct answer.
  4. To shift liability for accidents to subcontractors

Explanation

A safety program is a structured system for identifying hazards, training workers, and enforcing safe practices to prevent injuries and control costs. Its purpose is proactive loss prevention rather than merely satisfying a third party. Liability shifting and inspection reduction are not the goals of a safety program.

Question 5Business and Project Management

A contractor submits a bid bond with its proposal. What does a bid bond primarily guarantee to the owner?

  1. That the owner will pay promptly for completed work
  2. That subcontractor prices will not exceed the bid
  3. That the contractor will enter the contract and provide required performance security if awarded Correct answer.
  4. That the contractor will complete the project on schedule

Explanation

A bid bond assures the owner that the low bidder will sign the contract and furnish performance and payment bonds if selected. If the bidder fails to do so, the surety may be liable up to the bond penalty. It does not guarantee completion or subcontractor pricing.

Question 6Business and Project Management

Which document typically establishes the order of precedence among contract documents when they conflict?

  1. The project schedule
  2. The contractor's bid proposal form
  3. The subcontractor's quotation
  4. The general conditions of the contract Correct answer.

Explanation

The general conditions usually contain a precedence clause that ranks documents such as the agreement, general conditions, specifications, and drawings. This clause tells the parties which document governs in a conflict. Bid forms and schedules rarely carry precedence language.

Question 7Business and Project Management

What is the purpose of a retainage provision in a construction contract?

  1. To pay the architect's fees from the contractor's progress payments
  2. To cover the cost of permits issued by the local jurisdiction
  3. To hold back a percentage of payments as security until work is accepted Correct answer.
  4. To fund the contractor's general liability insurance

Explanation

Retainage withholds a portion of each progress payment to protect the owner until the work is complete and accepted. It provides leverage to ensure punch list items and closeout obligations are fulfilled. The withheld funds are later released per the contract terms.

Question 8Business and Project Management

A contractor's cost code structure is primarily used to do which of the following?

  1. Track and compare actual costs against the estimate by work item Correct answer.
  2. Calculate the owner's financing charges
  3. Assign each worker a payroll number
  4. Determine the project's critical path

Explanation

Cost codes break a project into work packages so field costs can be recorded and compared with the estimate. This lets managers spot overruns and forecast the cost to complete. Payroll numbering and scheduling are handled by separate systems.

Question 9Business and Project Management

A general contractor's estimate shows a total of $2,400,000 in direct costs. The company applies 12 percent for overhead and profit. What is the total bid amount?

  1. $2,640,000
  2. $2,880,000
  3. $2,688,000 Correct answer.
  4. $2,712,000

Explanation

Overhead and profit are applied to the direct cost base: $2,400,000 × 0.12 = $288,000. Adding that markup to direct costs gives $2,688,000. The other figures result from applying the percentage incorrectly or to the wrong base.

Question 10Business and Project Management

A contractor's estimate for a concrete package is $500,000 with a 15 percent contingency. During construction, actual costs reach $540,000. How is the contingency affected?

  1. It is untouched because contingency applies only to labor
  2. It is fully consumed and $40,000 of the contingency remains
  3. It is exceeded by $40,000 Correct answer.
  4. It must be doubled for the next phase

Explanation

The contingency is 15 percent of $500,000, or $75,000, giving a budget of $575,000. Actual costs of $540,000 leave $35,000 of contingency, so the overrun of $40,000 against the base estimate is absorbed within it, leaving $35,000, not $40,000. Comparing actual to base confirms the contingency covers the overrun but is not exceeded.

Question 11Business and Project Management

In a cost-plus-fee contract with a guaranteed maximum price, what happens when the contractor's costs exceed the GMP?

  1. The contractor generally absorbs costs above the GMP unless the contract provides otherwise Correct answer.
  2. The excess is deducted from the contractor's fee at year end
  3. The owner pays the excess automatically
  4. The GMP is automatically renegotiated upward

Explanation

A guaranteed maximum price caps the owner's exposure, and the contractor typically bears costs above that cap absent an approved change or savings-sharing clause. This shifts overrun risk to the contractor. The GMP is not automatically reopened.

Question 12Business and Project Management

A project has an activity with early start day 10, early finish day 18, late start day 14, and late finish day 22. What is the total float of this activity?

  1. 8 days
  2. 12 days
  3. 10 days
  4. 4 days Correct answer.

Explanation

Total float equals late finish minus early finish, or 22 − 18 = 4 days. It can also be found as late start minus early start, 14 − 10 = 4 days. Float measures how long the activity can slip without delaying project completion.

Question 13Business and Project Management

A contractor discovers that a subcontractor's scope excludes temporary power, which the general contractor assumed was included. What is the best first step to resolve the gap?

  1. Compare the subcontract documents and the project specifications to determine the intended allocation Correct answer.
  2. Terminate the subcontract for default
  3. Backcharge the subcontractor for the cost of temporary power
  4. Submit a change order to the owner for the full cost

Explanation

A scope gap should first be resolved by reviewing the subcontract and the prime contract documents to see where the work was assigned. That analysis determines whether the gap is a subcontractor omission, a general contractor oversight, or a missing owner scope item. Only then can the proper commercial remedy be chosen.

Question 14Business and Project Management

A contractor is evaluating a project with a 20 percent chance of a $100,000 loss and an 80 percent chance of a $50,000 gain. What is the expected monetary value?

  1. $30,000
  2. $20,000 Correct answer.
  3. $40,000
  4. $60,000

Explanation

Expected monetary value multiplies each outcome by its probability and sums the results: (0.20 × -$100,000) + (0.80 × $50,000) = -$20,000 + $40,000 = $20,000. The loss is negative, so the expected value is a positive $20,000.

Question 15Business and Project Management

An owner requires a performance bond and a payment bond. Which risk does the payment bond address?

  1. The risk that subcontractors and suppliers are not paid for labor and materials Correct answer.
  2. The risk of design errors by the architect
  3. The risk that the contractor's bid is withdrawn
  4. The owner's risk that the contractor fails to complete the work

Explanation

A payment bond protects subcontractors and suppliers by guaranteeing they will be paid for labor and materials furnished on the project. It also shields the owner from mechanics liens arising from nonpayment. Performance bonds, by contrast, address completion of the work.

Question 16Business and Project Management

A project is falling behind schedule because of repeated owner-directed design changes. Which claim basis is most appropriate for the contractor?

  1. Force majeure
  2. Differing site conditions
  3. Defective specifications discovered during bidding
  4. Constructive acceleration or delay caused by owner changes Correct answer.

Explanation

Owner-directed changes that delay the critical path can support a time extension or, if the owner refuses a proper extension while demanding the original date, a constructive acceleration claim. The contractor must document the change directives, schedule impact, and notice. Differing site conditions and force majeure address different causes.

Question 17Business and Project Management

Which scheduling technique explicitly accounts for resource constraints that may extend the project duration?

  1. Critical path method without leveling
  2. Resource-constrained scheduling Correct answer.
  3. Bar chart scheduling
  4. S-curve analysis

Explanation

Resource-constrained scheduling adjusts activity timing to respect limited crews or equipment, which can lengthen the project beyond the unconstrained critical path. CPM alone assumes unlimited resources. Bar charts and S-curves are presentation tools, not constraint-based scheduling methods.

Question 18Business and Project Management

A contractor's quality control plan requires inspection and testing at defined hold points. What is the purpose of a hold point?

  1. To document the final payment amount
  2. To record worker attendance
  3. To allow work to proceed without any inspection
  4. To require inspection and approval before the next phase of work may begin Correct answer.

Explanation

A hold point stops work at a defined stage until the required inspection or test is completed and approved. This prevents covering up defective work that would be costly to correct later. It is a control mechanism, not a payment or attendance record.

Question 19Business and Project Management

A project owner requests a change that adds work outside the original contract scope. What is the standard commercial mechanism to authorize it?

  1. A revised bid submitted by the contractor
  2. A verbal instruction confirmed at the next progress meeting
  3. A field work order signed by the superintendent only
  4. A written change order or contract modification executed per the contract Correct answer.

Explanation

Changes outside the original scope should be authorized through a written change order or modification following the contract's procedures. This documents scope, price, and time impact and preserves both parties' rights. Verbal or unilateral field instructions create disputes.

Question 20Business and Project Management

A contractor's earned value analysis shows CPI of 0.90 and SPI of 1.05. What does this indicate?

  1. The project is over budget and behind schedule
  2. The project is under budget and behind schedule
  3. The project is over budget and ahead of schedule Correct answer.
  4. The project is under budget and ahead of schedule

Explanation

A cost performance index below 1.0 means costs are running higher than the value earned, so the project is over budget. A schedule performance index above 1.0 means more work has been earned than planned, so it is ahead of schedule. Reading the two indices together gives the combined status.

Question 21Business and Project Management

A general contractor is deciding whether to self-perform or subcontract a specialty trade. Which factor most directly favors subcontracting?

  1. The trade is on the critical path
  2. The general contractor has idle crews trained in that trade
  3. The trade requires specialized equipment and expertise the general contractor lacks Correct answer.
  4. The owner prohibits subcontracting of any work

Explanation

Subcontracting is favored when the work requires specialized skills, equipment, or capacity the general contractor does not have in house. Specialty subcontractors bring that expertise and spread risk. Idle trained crews or critical path status do not by themselves favor subcontracting.

Question 22Business and Project Management

A contractor's bid is 8 percent below the next lowest bidder on a publicly bid project. What is the most prudent action before signing?

  1. Reduce the scope to match the bid
  2. Assume the next bidder made an error
  3. Sign immediately to secure the work
  4. Review the estimate for omissions or errors that could cause a loss Correct answer.

Explanation

An unusually low bid relative to competitors signals a possible estimating error, omission, or misunderstanding of scope. A prudent contractor reviews the estimate before committing, because a lump-sum contract will hold the contractor to the bid price. Signing without review exposes the firm to a serious loss.

Question 23Business and Project Management

A contractor is entitled to a time extension but the owner refuses and insists on the original completion date, forcing the contractor to add crews. What claim does this support?

  1. Differing site conditions
  2. Cardinal change
  3. Termination for convenience
  4. Constructive acceleration Correct answer.

Explanation

When the contractor is entitled to a time extension, the owner refuses it, and the contractor is compelled to accelerate to meet the original date, the resulting costs support a constructive acceleration claim. The contractor must show entitlement to the extension, a demand to accelerate, and actual acceleration costs. Cardinal change and differing site conditions address different situations.

Question 24Business and Project Management

A contractor's schedule shows two critical paths running in parallel. What is the primary management implication?

  1. Only one path needs tracking because the other is redundant
  2. Delays on either path can extend the project, so both require close monitoring Correct answer.
  3. Float is abundant and delays are unlikely to matter
  4. The project duration is determined by the shorter path

Explanation

When multiple paths share the longest duration, each is critical and zero float applies to all of them. A delay on any one of them extends the project, so management attention and contingency must cover both. Redundancy does not make either path safe to ignore.

Question 25Business and Project Management

A subcontract contains a pay-when-paid clause. How does this clause typically affect the subcontractor's right to payment?

  1. It makes the owner's payment to the general contractor a condition of the subcontractor's payment, subject to applicable law Correct answer.
  2. It transfers the owner's payment obligation directly to the subcontractor
  3. It guarantees payment within 30 days regardless of owner payment
  4. It eliminates the subcontractor's right to a mechanics lien

Explanation

A pay-when-paid clause ties the timing of the subcontractor's payment to the general contractor's receipt of owner payment. Its enforceability and interpretation vary by jurisdiction and contract language, so local law must be checked. It does not eliminate lien rights or create direct owner liability.

Question 26Business and Project Management

Under a standard AIA-style contract, the contractor's application for payment is certified by the architect and the owner must pay within a stated period. If the owner fails to pay within that period, what is the contractor's typical contractual remedy after providing proper notice?

  1. Suspend performance and pursue interest on the unpaid amount as provided in the contract Correct answer.
  2. Automatically terminate the contract without notice
  3. Record a mechanic's lien only after substantial completion
  4. Reduce the contract sum by the unpaid amount

Explanation

Construction contracts generally condition the contractor's right to suspend or stop work on prior written notice and a defined cure period after nonpayment. Most forms also entitle the contractor to interest on late certified payments at a contractual rate. Termination is usually a separate, more demanding remedy requiring notice and an opportunity to cure.

Question 27Business and Project Management

A general contractor is preparing the project closeout package. Which item is most directly required to demonstrate that the owner's property is free of subcontractor and supplier claims before final payment?

  1. The as-built drawings stamped by the contractor
  2. Final lien waivers and a contractor's affidavit of payment of debts and claims Correct answer.
  3. A punch list signed by the architect
  4. The certificate of substantial completion

Explanation

Final conditional or unconditional lien waivers from subcontractors and suppliers, together with the contractor's sworn affidavit that debts and claims are paid, are the standard closeout instruments protecting the owner from mechanics' liens. The affidavit typically accompanies the final application for payment.

Question 28Business and Project Management

A general contractor's superintendent reports that a subcontractor has repeatedly failed toolbox safety talks and is working without fall protection on an elevated deck. Which action best reflects the general contractor's contractual safety responsibility on a multi-employer site?

  1. Refer the matter to the owner's safety consultant and await instructions
  2. Document the condition in the daily log and continue work to avoid delay
  3. Stop the affected work, direct correction, and issue a written notice invoking the subcontract's safety and removal provisions Correct answer.
  4. Notify the subcontractor's home office in writing and take no further action until a reply is received

Explanation

The general contractor typically controls the site and holds the subcontract, so it must enforce safety compliance, including the right to stop unsafe work and remove noncompliant personnel. Immediate abatement plus written notice preserves both safety and the contractual record for backcharges or default.

Question 29Business and Project Management

During preconstruction, an owner asks the general contractor to provide a construction manager at-risk (CMAR) delivery. What distinguishes CMAR from pure agency construction management?

  1. The CMAR designs the project and self-performs all major trades
  2. The CMAR acts only as the owner's adviser and holds no trade contracts
  3. The CMAR is paid exclusively from savings against the owner's budget
  4. The CMAR holds the trade contracts and guarantees a maximum price, bearing cost risk Correct answer.

Explanation

In CMAR delivery the construction manager contracts directly with the trades and provides a guaranteed maximum price, so it assumes cost risk much like a general contractor. Agency CM acts only as the owner's representative and the owner holds the trade contracts.

Question 30Business and Project Management

A general contractor's bid includes a stated allowance for owner-selected light fixtures. How should the contractor administer this allowance during construction?

  1. Adjust the contract sum by change order for the difference between the allowance and the actual cost of the selected fixtures Correct answer.
  2. Require the owner to purchase the fixtures outside the contract
  3. Absorb any overage in the contractor's overhead
  4. Treat the allowance as a fixed lump sum that cannot be adjusted

Explanation

A cash allowance establishes a budgeted amount in the contract; the actual cost of the owner-selected item is reconciled against it and the difference is handled by change order. The contractor's markup on the allowance is typically limited to what the contract specifies.

Question 31Business and Project Management

A subcontractor submits a claim for extra work performed under a verbal direction from the general contractor's field superintendent. Which fact is most important in determining whether the claim is compensable?

  1. Whether the superintendent had contractual authority to direct changes and whether written notice was later given Correct answer.
  2. Whether the subcontractor's crew was unionized
  3. Whether the extra work was performed on a weekend
  4. Whether the owner's representative observed the work

Explanation

Change authority is defined in the contract, and many forms limit field personnel to directing minor work while requiring written confirmation for changes affecting price or time. A verbal directive may still be compensable, but the notice provisions and the superintendent's actual authority govern.

Question 32Business and Project Management

A general contractor is developing the project schedule and must decide how to represent a long-lead electrical switchgear package. Which approach best communicates the procurement risk to the owner?

  1. Rely on the manufacturer's standard lead time without adjustment for submittal review
  2. Show the procurement as a single activity with no float or predecessor logic
  3. Omit the procurement activity and assume delivery on the first day of installation
  4. Model submittal, fabrication, and delivery as linked activities with realistic durations and identified float Correct answer.

Explanation

Procurement activities should be broken into submittal, approval, fabrication, and delivery, each with logic ties so the schedule reflects real lead times and float. This makes the risk visible and lets the team manage release dates and expediting.

Question 33Business and Project Management

A general contractor's project is entering the commissioning phase. What is the contractor's primary responsibility relative to the commissioning authority?

  1. Delegate all commissioning decisions to the design team
  2. Set the commissioning scope independently of the contract documents
  3. Complete and verify systems installation, provide documentation, and support functional performance testing Correct answer.
  4. Certify that the owner's operating staff is fully trained

Explanation

The contractor installs and verifies systems per the contract documents, supplies O&M data and test documentation, and supports the commissioning authority during functional testing. The commissioning authority directs the process but does not assume the contractor's installation responsibility.

Question 34Business and Project Management

An owner proposes to pay a general contractor on a cost-plus-percentage-of-cost basis. Why is this fee structure generally disfavored or prohibited on public work?

  1. It is only permitted when a performance bond is waived
  2. It eliminates the contractor's obligation to keep cost records
  3. It gives the contractor an incentive to increase costs because the fee grows with every dollar spent Correct answer.
  4. It requires the contractor to disclose subcontractor bids

Explanation

A percentage-of-cost fee rises as costs rise, removing the contractor's incentive to control cost and creating a conflict of interest. Many public statutes prohibit it, and cost-plus-fixed-fee is used instead to avoid the incentive problem.

Question 35Business and Project Management

A general contractor is required to submit a schedule of values with its first payment application. What is the primary purpose of this schedule?

  1. To document the contractor's safety plan
  2. To allocate the contract sum across work items so progress payments can be measured fairly Correct answer.
  3. To list the subcontractors' license numbers
  4. To establish the project's critical path

Explanation

The schedule of values breaks the contract sum into work items with assigned values, allowing the architect and owner to evaluate the percentage of completion claimed in each payment application. It should be front-loaded cautiously and must total the contract sum.

Question 36Business and Project Management

During construction, the owner requests that the general contractor accelerate the work to recover three weeks of delay caused by the owner's late design release. Which basis best supports the contractor's acceleration claim?

  1. Constructive acceleration arising from the owner's refusal to grant a time extension for owner-caused delay Correct answer.
  2. A cardinal change that voids the entire contract
  3. Superior knowledge held by the owner about market pricing
  4. Differing site conditions discovered during excavation

Explanation

When the owner causes excusable delay, refuses a proper time extension, and insists on the original date, the contractor may be entitled to recover the cost of accelerating. The claim rests on the owner's failure to recognize excusable delay rather than on changed conditions or a cardinal change.

Question 37Business and Project Management

A general contractor is negotiating a subcontract and wants to limit its exposure to consequential damages arising from a subcontractor's delay. Which provision best accomplishes this?

  1. A clause making the subcontract subject to the prime contract
  2. A clause requiring the subcontractor to carry general liability insurance
  3. A clause requiring weekly progress reports from the subcontractor
  4. A mutual waiver of consequential damages with a liquidated damages backcharge for delay Correct answer.

Explanation

A mutual waiver of consequential damages limits each party's exposure to indirect losses, while a liquidated damages backcharge gives the general contractor a defined recovery for delay. Together they cap and quantify the risk more predictably than insurance or reporting requirements.

Question 38Business and Project Management

A general contractor's quality assurance program calls for first-delivery inspections of materials. What is the primary business purpose of this practice?

  1. To shift responsibility for defects to the supplier's insurer
  2. To reduce the number of submittals required
  3. To satisfy the architect's personal preference for site visits
  4. To detect nonconforming materials before installation, avoiding costly rework and schedule impact Correct answer.

Explanation

Inspecting materials on first delivery catches nonconformances before they are incorporated into the work, when removal and replacement are far cheaper. It is a preventive control that protects cost and schedule rather than a submittal-reduction device.

Question 39Business and Project Management

A general contractor's project has a labor productivity variance that is unfavorable while material costs are on budget. Which analysis best identifies the root cause before corrective action is chosen?

  1. Recalculate the contractor's overhead rate for the year
  2. Compare earned labor hours against actual hours by cost code and work package to isolate the affected activities Correct answer.
  3. Check whether the bonding capacity has been exceeded
  4. Review the owner's financing costs for the project

Explanation

Productivity problems are diagnosed by comparing earned hours to actual hours at the cost-code and work-package level, which localizes the variance to specific activities. Only after identifying the affected work can the team determine whether the cause is supervision, sequencing, or rework.

Question 40Business and Project Management

A general contractor is preparing a bid and must decide how to price a risk it cannot quantify well, such as potential winter weather downtime. Which pricing approach is most appropriate?

  1. Add an arbitrary percentage to every line item without documentation
  2. Exclude the risk entirely and rely on a claim later
  3. Include a defined contingency in the estimate for the identified risk and document the assumption Correct answer.
  4. Price the risk into the fee so it appears as profit

Explanation

A documented contingency tied to an identified risk lets the estimate carry a defensible allowance that can be managed and released as the risk passes. Undocumented padding or relying on future claims is poor practice and weakens the contractor's position.

Question 41Estimating and Plan Reading

On a commercial plan set, a dimension string reads 24'-6". What is this dimension expressed in decimal feet?

  1. 24.60 ft
  2. 24.50 ft Correct answer.
  3. 24.05 ft
  4. 24.06 ft

Explanation

The six inches after the dash is a fraction of a foot, and 6 inches equals 0.5 foot, so 24'-6" converts to 24.50 decimal feet. Feet-and-inches notation uses the apostrophe for feet and the quote for inches, so the inches must be divided by 12.

Question 42Estimating and Plan Reading

In a typical architectural drawing title block, what does the scale notation 1/4" = 1'-0" indicate?

  1. One-quarter inch on the drawing represents one foot of actual construction Correct answer.
  2. The drawing is one-quarter of full size in every dimension
  3. The sheet must be plotted at 25 percent enlargement
  4. One-quarter foot on the drawing represents one inch of actual construction

Explanation

Architectural scales are written as drawn-unit equals real-unit, so 1/4 inch on paper corresponds to 12 inches in the field. That makes the drawing 1/48 of full size, not one-quarter size.

Question 43Estimating and Plan Reading

Which CSI MasterFormat division number is assigned to Concrete?

  1. Division 04
  2. Division 05
  3. Division 03 Correct answer.
  4. Division 09

Explanation

MasterFormat places Concrete in Division 03, which is where cast-in-place, precast, and concrete reinforcement specifications are organized. Knowing the division numbers helps an estimator find the right specification sections quickly.

Question 44Estimating and Plan Reading

A plan note calls for a 4-inch slab on grade over 6 mil vapor retarder. Which quantity does the 6 mil value describe?

  1. The depth of the subgrade base course
  2. The thickness of the concrete slab
  3. The width of the perimeter insulation
  4. The thickness of the vapor retarder membrane Correct answer.

Explanation

The mil is a thickness unit equal to one-thousandth of an inch, and 6 mil describes the polyethylene vapor retarder placed under the slab. The slab thickness is separately stated as 4 inches.

Question 45Estimating and Plan Reading

A drawing legend shows a line with a long dash and two short dashes repeated. What does this linetype most commonly indicate on a floor plan?

  1. A property line at the site boundary
  2. A section cut line
  3. A hidden or overhead feature above the cut plane Correct answer.
  4. A centerline of a structural member

Explanation

Dashed and broken linetypes conventionally indicate elements that are hidden from view or located above the cut plane, such as overhead beams or soffits. Solid lines usually show visible edges at the cut plane.

Question 46Estimating and Plan Reading

A wall section detail is drawn at 1 1/2" = 1'-0". A component measures 3 inches long on the printed sheet. What is its actual length?

  1. 1 foot 6 inches
  2. 4 feet
  3. 6 feet
  4. 2 feet Correct answer.

Explanation

At 1 1/2 inches per foot, each 1.5 inches on paper equals 12 inches in reality. Three inches on paper is two full 1.5-inch increments, so the real length is 2 feet.

Question 47Estimating and Plan Reading

What does a callout bubble containing the number 12 above a line and 04 below the line typically mean?

  1. Detail 12 on sheet 4 Correct answer.
  2. Room 12 in Building 4
  3. Sheet 12 of a 4-sheet set
  4. Revision 12 dated April

Explanation

The standard detail reference places the detail number above the horizontal line and the sheet number below it. So the bubble points the reader to Detail 12 on Sheet 4.

Question 48Estimating and Plan Reading

A takeoff shows 1,850 square feet of 5/8-inch gypsum board and the estimator applies a 10 percent waste factor. How many square feet should be ordered?

  1. 2,590 sf
  2. 1,860 sf
  3. 2,220 sf
  4. 2,035 sf Correct answer.

Explanation

A 10 percent waste factor multiplies the net quantity by 1.10, so 1,850 times 1.10 equals 2,035 square feet. Waste covers cuts, breakage, and layout losses beyond the measured area.

Question 49Estimating and Plan Reading

A concrete foundation wall is 60 feet long, 8 inches thick, and 4 feet high. Ignoring waste, how many cubic yards of concrete are required?

  1. 17.78 cy
  2. 5.93 cy Correct answer.
  3. 7.11 cy
  4. 1.98 cy

Explanation

Convert to feet: 8 inches equals 0.667 foot. Volume is 60 times 0.667 times 4, which equals 160 cubic feet, and dividing by 27 gives about 5.93 cubic yards.

Question 50Estimating and Plan Reading

A roof plan shows a gable roof with a 6:12 slope. What is the approximate slope angle from horizontal?

  1. 22.6 degrees
  2. 26.6 degrees Correct answer.
  3. 45.0 degrees
  4. 30.0 degrees

Explanation

A 6:12 slope means 6 units of rise per 12 units of run, so the tangent of the angle is 0.5. The arctangent of 0.5 is approximately 26.6 degrees.