I85PREP
⌘ K
UT General Contractor study materials
UT General Contractor study resources

UT General Contractor practice questions

One question at a time. Build your UT General Contractor understanding.

First 50 of 200 questions. Each one lists the choices, the correct answer, and an explanation. The checker at the top of this page saves progress in this browser when it is available.

Continue in the practice tool above to load more questions, 50 at a time.

Question 1Business and Project Management

Under Utah law, a contractor must hold a contractor license from DOPL when the total contract price for a construction project is:

  1. At least $50,000
  2. At least $10,000
  3. At least $3,000 Correct answer.
  4. Any dollar amount

Explanation

Utah requires a contractor license from the Division of Professional Licensing for construction work when the project value reaches $3,000. Below that threshold, a license is generally not required.

Question 2Business and Project Management

What does a performance bond primarily do for the owner on a construction project?

  1. It replaces builder's risk insurance
  2. It guarantees that suppliers and subcontractors get paid
  3. It protects the owner from contractor default Correct answer.
  4. It sets the contractor's profit margin

Explanation

A performance bond guarantees the owner that the contractor will complete the contract; if the contractor defaults, the surety steps in or pays the bond amount. Payment to suppliers and subcontractors is handled by a separate payment bond.

Question 3Business and Project Management

The owner verbally directs the contractor to perform work that is clearly outside the contract scope. What is the best business practice for the contractor?

  1. Obtain a signed written change order before proceeding Correct answer.
  2. Invoice for the work only at final completion
  3. Refuse to do any extra work under any circumstances
  4. Perform the work and rely on the verbal direction

Explanation

Extra work outside the contract scope should be authorized in writing before it is performed so the contractor has enforceable proof of the owner's direction and the agreed price. Verbal directions are difficult to prove and often lead to payment disputes.

Question 4Business and Project Management

A Utah construction employer with employees must carry which coverage to pay benefits for work-related injuries?

  1. A builder's risk policy
  2. Commercial general liability insurance
  3. Workers' compensation insurance Correct answer.
  4. An umbrella liability policy

Explanation

Utah employers must carry workers' compensation coverage for employees, which provides benefits for work-related injuries and generally limits the employer's tort exposure to those injuries.

Question 5Business and Project Management

In the critical path method, the critical path is best described as:

  1. The path that starts with the first activity
  2. The longest path, which sets the project duration Correct answer.
  3. The path with the highest total cost
  4. The path that contains the greatest number of separate activities

Explanation

The critical path is the longest path through the network; its total duration equals the shortest possible project completion time. Any delay on a critical activity delays the project.

Question 6Business and Project Management

In a construction schedule, total float (slack) is:

  1. Slack time that will not delay project completion Correct answer.
  2. The total calendar time allowed for the whole project
  3. The gap between the bid and the final cost
  4. The full duration of the activity itself

Explanation

Total float is the amount of time an activity can be delayed without delaying the project completion date. Critical activities have zero total float.

Question 7Business and Project Management

Commercial general liability (CGL) insurance on a construction project typically responds to:

  1. Third-party bodily injury and property damage claims Correct answer.
  2. The contractor's errors in design
  3. Injuries to the contractor's own employees on the job
  4. Damage to the contractor's own tools

Explanation

CGL insurance covers the insured's liability for bodily injury or property damage to third parties caused by the insured's operations. It does not cover the contractor's own employees, own equipment, or professional design errors.

Question 8Business and Project Management

Retainage on a construction contract is:

  1. A percentage withheld from each progress payment Correct answer.
  2. A deposit the contractor pays when signing the contract
  3. A penalty the owner charges for late completion
  4. The final payment released at closeout

Explanation

Retainage is a percentage of each progress payment withheld by the owner until completion or another agreed point, giving the owner leverage to ensure the work is finished and deficiencies are corrected.

Question 9Business and Project Management

For a Utah contractor license, the 'qualifier' is the individual who:

  1. Is a DOPL employee assigned to inspect each project
  2. Is the largest shareholder, regardless of construction experience
  3. Meets experience rules and is responsible for the work Correct answer.
  4. Holds the surety bond that the contractor must post with the state

Explanation

The qualifier is the person who meets DOPL's experience requirements and is responsible for the licensee's construction work. The license is tied to that individual, so losing the qualifier can affect the license.

Question 10Business and Project Management

A subcontractor on a private Utah project wants to preserve full mechanic's lien rights. The subcontractor should generally give preliminary notice to the owner within:

  1. 10 days before starting work on the project
  2. 90 days after the last day of furnishing labor or materials
  3. 180 days after recording the lien
  4. 20 days after first furnishing labor or materials Correct answer.

Explanation

On private Utah projects, a subcontractor or supplier should give preliminary notice to the owner within 20 days after first furnishing labor or materials to preserve full lien rights. A late notice generally limits the lien to amounts unpaid at the time of the notice.

Question 11Business and Project Management

A supplier last furnishes materials to a private Utah project on June 1. To preserve its lien, the notice of lien must generally be recorded:

  1. Within 90 days after last furnishing labor or materials Correct answer.
  2. 30 days after the date the contract was signed by both parties
  3. One year after substantial completion
  4. 180 days after last furnishing labor or materials

Explanation

A Utah construction lien must be recorded within 90 days after the claimant last furnishes labor or materials to the project. Recording later generally forfeits the lien.

Question 12Business and Project Management

After a construction lien has been recorded on a Utah project, an action to foreclose the lien must be commenced within:

  1. 90 days after the lien is recorded
  2. Two years after substantial completion
  3. 180 days after the lien is recorded Correct answer.
  4. 30 days after the lien is recorded

Explanation

Utah requires a foreclosure action on a construction lien to be commenced within 180 days after the lien is recorded. If no action is timely filed, the lien becomes void.

Question 13Business and Project Management

A payment bond on a construction project protects:

  1. The contractor against design errors
  2. Unpaid subcontractors and suppliers Correct answer.
  3. The lender against borrower default
  4. The owner if the contractor abandons the project

Explanation

A payment bond guarantees that subcontractors and suppliers will be paid for labor and materials furnished on the project if the contractor fails to pay them. Protection against contractor default is provided by a performance bond.

Question 14Business and Project Management

A bid bond submitted with a construction bid assures the owner that:

  1. The bidder will sign the contract and furnish bonds Correct answer.
  2. All subcontractors will be paid in full
  3. The design documents are free of errors
  4. The completed project will be finished on schedule

Explanation

A bid bond assures the owner that the successful bidder will execute the contract and provide the required performance and payment bonds. If the bidder refuses, the surety pays the owner up to the bid bond amount.

Question 15Business and Project Management

Under a surety indemnity agreement, the contractor agrees that:

  1. The bond automatically expires at substantial completion
  2. The contractor must reimburse the surety for losses it pays Correct answer.
  3. The surety must pay all claims without seeking reimbursement
  4. The owner must indemnify the subcontractors

Explanation

An indemnity agreement requires the contractor (the indemnitor) to reimburse the surety for any losses, costs, and expenses the surety incurs on the bond. This is how the surety is protected when it must pay a claim.

Question 16Business and Project Management

A construction contract provides for liquidated damages of $1,000 per day for late completion. Such a provision is best described as:

  1. An amount that must be proven at trial
  2. A reasonable pre-estimate of damages for late completion Correct answer.
  3. A punitive charge designed to punish a late contractor
  4. A bonus paid for finishing early

Explanation

Liquidated damages are a pre-agreed amount per day of delay that estimates the owner's actual losses when they are difficult to calculate. They are enforceable if reasonable and not a penalty.

Question 17Business and Project Management

Fast-tracking a construction project means:

  1. Adding extra crews and overtime to shorten an activity
  2. Overlapping design and construction to shorten the schedule Correct answer.
  3. Re-sequencing activities without overlapping
  4. Removing scope to meet the completion date

Explanation

Fast-tracking compresses the schedule by overlapping design and construction phases so construction can begin before design is fully complete. Adding resources to shorten an activity is crashing.

Question 18Business and Project Management

A contractor marks up a $50,000 cost by 20%. The resulting gross margin percentage on the selling price is closest to:

  1. 10.0%
  2. 25.0%
  3. 16.7% Correct answer.
  4. 20.0%

Explanation

The selling price is $50,000 × 1.20 = $60,000. Gross margin is the profit divided by the selling price: ($60,000 − $50,000) ÷ $60,000 = 16.7%.

Question 19Business and Project Management

A contractor has current assets of $300,000 and current liabilities of $150,000. The current ratio is:

  1. 3.0
  2. 0.5
  3. 1.5
  4. 2.0 Correct answer.

Explanation

The current ratio equals current assets divided by current liabilities: $300,000 ÷ $150,000 = 2.0. It measures the contractor's ability to meet short-term obligations.

Question 20Business and Project Management

A subcontractor repeatedly fails to perform and ignores notices to cure. The general contractor's best response is to:

  1. Pay the subcontractor in full and hire a second sub
  2. Ask the owner to terminate the prime contract
  3. Terminate the sub and back-charge excess completion cost Correct answer.
  4. Continue paying the sub until the project is complete

Explanation

When a subcontractor defaults, the contractor may terminate the subcontract, hire a replacement, and back-charge the excess cost of completing the work, provided the subcontract's notice and cure provisions are followed.

Question 21Business and Project Management

A 'flow-down' clause in a subcontract is intended to:

  1. Flow prime contract duties down to the subcontractor Correct answer.
  2. Shift all owner risk to the subcontractor
  3. Eliminate the need for any bonds on the project
  4. Allow the sub to file a lien against the owner

Explanation

Flow-down clauses incorporate the prime contract's duties, rights, and standards into the subcontract so the subcontractor is bound by the same obligations that bind the general contractor. They do not transfer unrelated risks or change lien or bonding law.

Question 22Business and Project Management

A contractor's daily job reports are most valuable for:

  1. Replacing the project schedule
  2. Documenting delays, weather, and extra work Correct answer.
  3. Marketing the company to prospective clients
  4. Calculating employee payroll taxes

Explanation

Daily reports create a contemporaneous record of weather, manpower, delays, and extra work, which supports change orders, delay claims, and dispute resolution. They supplement but do not replace the schedule.

Question 23Business and Project Management

An arbitration clause in a construction contract generally means that:

  1. A neutral arbitrator decides, and the award is usually binding Correct answer.
  2. The clause is unenforceable in construction
  3. Only the owner may file a claim
  4. All claims against the owner are waived

Explanation

Arbitration sends disputes to a neutral third party, and the resulting award is generally final and binding, with only limited court review. It does not waive claims or limit who may bring them.

Question 24Business and Project Management

A contractor forms a limited liability company to operate the construction business. A key advantage of this structure is that:

  1. The company pays no federal income tax
  2. Owners are generally shielded from business debts Correct answer.
  3. The business cannot be sued
  4. Owners must personally guarantee all jobs

Explanation

An LLC generally shields its owners from personal liability for business debts and claims, although personal guarantees can override that protection. It does not eliminate taxes or make the business immune from suit.

Question 25Business and Project Management

A worker sets his own hours, uses his own tools, is paid by the job, and is not controlled by the contractor. This worker is most likely:

  1. A statutory employee
  2. A borrowed servant
  3. An independent contractor Correct answer.
  4. An employee of the contractor

Explanation

Workers who control their own hours, methods, and tools and are paid by the job are generally independent contractors rather than employees. Misclassification can create liability for payroll taxes, workers' compensation, and penalties.

Question 26Business and Project Management

In the critical path method of scheduling, the critical path is best described as:

  1. The longest continuous chain of dependent activities through the network Correct answer.
  2. The sequence of activities that carries the highest total material cost
  3. The chain of activities that has the largest amount of total float available
  4. The chain of activities that contains the greatest number of separate tasks

Explanation

The critical path is the longest path through the network, and its length establishes the shortest possible project duration. Activities on that path have no total float, so any slippage there slips the project completion date.

Question 27Business and Project Management

In the traditional design-bid-build delivery method, how are the contracts structured?

  1. The owner contracts separately with a design professional and with a contractor selected by competitive bidding Correct answer.
  2. One firm holds a single contract to design and build the project for a lump sum
  3. The contractor hires the design professional and is responsible for design errors
  4. The owner contracts only with a construction manager who self-performs every trade

Explanation

Design-bid-build separates design from construction: the owner holds one contract with the designer and a separate contract with the low bidder. This separation means the designer prepares the documents on which contractors bid.

Question 28Business and Project Management

A change order on a construction contract is:

  1. A verbal direction from the superintendent that authorizes extra work
  2. A schedule revision issued by the contractor after a delay occurs
  3. A written modification, signed by the owner and contractor, that changes scope, price, or time Correct answer.
  4. A letter from the contractor requesting clarification of the drawings

Explanation

A change order is the formal written instrument that alters the contract's scope, contract sum, or contract time. Most contracts require it to be signed by authorized representatives of both parties before the changed work is performed or as ratification afterward.

Question 29Business and Project Management

A request for information (RFI) on a construction project is used to:

  1. Formally reject work that does not conform to the specifications
  2. Give notice that the contractor intends to claim additional cost
  3. Obtain a written interpretation or clarification of the contract documents from the designer Correct answer.
  4. Ask the owner for a copy of the payment bond

Explanation

An RFI is the formal mechanism for the contractor to ask the designer to interpret or clarify the drawings and specifications. The written answer becomes part of the project record and may later support a change order if the clarification alters cost or time.

Question 30Business and Project Management

The primary purpose of requiring the contractor to submit shop drawings and product data for review is to:

  1. Document craft payroll for certified payroll reporting
  2. Show how the contractor proposes to meet the design requirements so the designer can review it before fabrication or installation Correct answer.
  3. Transfer responsibility for design errors from the designer to the contractor
  4. Record the quantity of each material delivered to the site

Explanation

Submittals demonstrate that the contractor's intended products and fabrication details conform to the design concept and specifications. Review by the designer is for conformance with the design intent and does not relieve the contractor of responsibility for the completeness of the submittal.

Question 31Business and Project Management

Contractor licensing in Utah is administered by which agency?

  1. The Utah Division of Occupational and Professional Licensing Correct answer.
  2. The Utah Attorney General's office
  3. The Utah Department of Transportation
  4. The Utah Division of Facilities Construction and Management

Explanation

The Division of Occupational and Professional Licensing (DOPL) issues and regulates contractor licenses in Utah. A contractor must hold the appropriate license before entering into a contract for construction work, and the license is held by the business entity with a qualifying individual.

Question 32Business and Project Management

A punch list prepared near the end of a project is:

  1. A list of incomplete or defective items that the contractor must correct before final completion Correct answer.
  2. A log of all change orders issued during construction
  3. A roster of subcontractors and their assigned scopes of work
  4. A schedule of values used to support progress payments

Explanation

The punch list is developed during the substantial completion inspection and records work that is incomplete, damaged, or not conforming. Correction of those items is a condition of final completion and final payment.

Question 33Business and Project Management

Substantial completion of a construction project occurs when:

  1. The work is complete enough for its intended use even though minor items remain Correct answer.
  2. The building official issues a certificate of occupancy
  3. The owner first occupies any part of the project, regardless of the work remaining
  4. The contractor's final payment application is approved by the lender

Explanation

Substantial completion is the stage at which the work is sufficiently complete for the owner's intended use, with only minor punch list items outstanding. It typically starts warranty periods and shifts risk of loss and insurance responsibility to the owner, even though final completion and final payment come later.

Question 34Business and Project Management

A subcontract makes the owner's payment to the general contractor a condition precedent to the general contractor's duty to pay the subcontractor. This provision:

  1. Shifts the risk of owner nonpayment onto the subcontractor Correct answer.
  2. Requires the owner to pay the subcontractor directly
  3. Is unenforceable because subcontractors cannot waive payment rights
  4. Affects only the timing of payment and leaves the risk of nonpayment with the general contractor

Explanation

A pay-if-paid clause makes owner payment a condition precedent, so the subcontractor bears the risk of owner nonpayment. A pay-when-paid clause, by contrast, addresses only the timing of payment and does not permanently transfer that risk.

Question 35Business and Project Management

Compared with a CPM network diagram, a simple bar (Gantt) chart has the significant limitation that it:

  1. Does not clearly display the logical dependencies between activities Correct answer.
  2. Cannot be updated once construction begins
  3. Is usable only on projects scheduled to finish within one year
  4. Cannot show the planned start and finish dates of activities

Explanation

A bar chart displays durations against a calendar but does not show the logic ties that drive sequencing. Without that logic, the effects of a delay on later work are hard to trace, which is why CPM networks are preferred for delay analysis.

Question 36Business and Project Management

Resource leveling is best described as:

  1. Shifting noncritical activities within their available float to reduce peak resource demand Correct answer.
  2. Removing activities from the schedule to reduce project cost
  3. Compressing the schedule by adding overtime to critical activities
  4. Assigning critical path activities to the lowest-bidding subcontractor

Explanation

Resource leveling smooths peaks and valleys in labor or equipment demand by moving activities within their float. If the available float is insufficient to absorb the shift, leveling can extend the project duration.

Question 37Business and Project Management

Budgeted cost of work performed is $80,000 and actual cost of work performed is $100,000. What is the cost performance index, and what does it indicate?

  1. 0.80, and the project is over budget Correct answer.
  2. 0.80, and the project is under budget
  3. 1.25, and the project is under budget
  4. 1.25, and the project is over budget

Explanation

The cost performance index equals earned value divided by actual cost, or $80,000 divided by $100,000, which is 0.80. A CPI below 1.00 means each dollar spent is buying less than a dollar of earned value, so the work is running over budget.

Question 38Business and Project Management

Under a cost-plus contract with a guaranteed maximum price (GMP), the contractor:

  1. Forfeits the entire fee once costs reach the guaranteed maximum
  2. Receives a fixed lump sum regardless of what the work actually costs
  3. Is paid all costs with no upper limit while the owner keeps all savings
  4. Is reimbursed allowable costs plus a fee, with the owner's total price capped and savings often shared Correct answer.

Explanation

A GMP arrangement reimburses the contractor for allowable costs and an agreed fee while placing a ceiling on the owner's total price. Costs above the GMP are generally the contractor's responsibility, and any savings below it are often split under a sharing formula.

Question 39Business and Project Management

An owner denies a properly supported request for a time extension caused by unusually severe weather but insists the original completion date be met. The contractor adds a second shift to recover the lost time. This situation is best characterized as:

  1. Constructive acceleration Correct answer.
  2. Concurrent delay
  3. A suspension of work
  4. A cardinal change

Explanation

Constructive acceleration occurs when the contractor is entitled to a time extension, the owner refuses it, and the owner nonetheless demands the original completion date. The contractor may then recover the reasonable cost of the added crews needed to regain the schedule.

Question 40Business and Project Management

During excavation a contractor encounters bedrock far above the elevation shown in the geotechnical information included in the contract documents. What should the contractor do first?

  1. Give prompt written notice to the owner before the condition is further disturbed Correct answer.
  2. Halt all work on the project until the owner files suit
  3. Continue excavating and include the extra cost in the next pay application
  4. Re-bid the excavation package to specialty subcontractors

Explanation

Differing site condition clauses require the contractor to notify the owner promptly and before the condition is disturbed so the owner and designer can inspect it. Giving that notice preserves the contractor's right to an equitable adjustment in price and time.

Question 41Business and Project Management

A contract requires written notice of a delay within seven days, but the contractor waits thirty days. The most likely result is that:

  1. The delay claim may be denied or limited because of the untimely notice Correct answer.
  2. The owner's silence automatically waives the notice requirement
  3. The claim must be paid in full because the delay actually occurred
  4. The contractor recovers only for delay days occurring after the notice

Explanation

Many construction contracts treat notice provisions as conditions precedent to a claim, and courts commonly enforce them unless the owner has waived the requirement. Late notice therefore creates a substantial risk that the claim is barred or reduced, even when the underlying delay is genuine.

Question 42Business and Project Management

An addendum issued three days before bid opening is intended to:

  1. Change or clarify the bidding documents before bids are opened, with acknowledgment required from bidders Correct answer.
  2. Direct correction of defective work discovered during construction
  3. Modify the contract after it has been awarded and signed
  4. Extend the warranty period after substantial completion

Explanation

An addendum is issued during the bidding phase to correct, clarify, or change the solicitation before bids are opened. Bidders are normally required to acknowledge each addendum in their bid, and failure to do so can render a bid nonresponsive.

Question 43Business and Project Management

On a unit-price contract, the amount ultimately paid to the contractor is based on:

  1. The owner's original estimated quantities multiplied by the unit prices
  2. The contractor's actual costs plus an agreed percentage fee
  3. The lump sum bid, adjusted only by executed change orders
  4. The actual measured quantities of work performed multiplied by the bid unit prices Correct answer.

Explanation

A unit-price contract pays for measured quantities of work at the bid unit prices, so the final contract amount varies with actual quantities. This is why unit-price contracts are common where quantities cannot be determined accurately in advance, such as earthwork.

Question 44Business and Project Management

A contractor reports current assets of $420,000 and current liabilities of $260,000. What is the amount of working capital?

  1. $160,000 Correct answer.
  2. $680,000
  3. $260,000
  4. $420,000

Explanation

Working capital equals current assets minus current liabilities, or $420,000 minus $260,000, which is $160,000. It measures the liquid cushion available to fund day-to-day operations such as payroll and materials before payments are collected.

Question 45Business and Project Management

A surety's prequalification of a contractor before issuing performance and payment bonds focuses primarily on:

  1. The contractor's financial strength, experience, and capacity to complete the bonded work Correct answer.
  2. The number of workers the contractor intends to hire for the job
  3. The contractor's equipment inventory and yard layout
  4. The contractor's marketing plan and bidding strategy

Explanation

The surety is assuming the risk of contractor default, so it underwrites the contractor's balance sheet, banking relationships, backlog, and demonstrated ability to perform similar work. Bonding capacity reflects that underwriting judgment rather than marketing or staffing preferences alone.

Question 46Business and Project Management

Owner-caused and contractor-caused delays run over the same period, and either one alone would have pushed completion past the contract date. Under the common rule applied to concurrent delay, the contractor generally:

  1. Receives a time extension but not delay damages for the concurrent period Correct answer.
  2. Receives both a time extension and delay damages for the full period
  3. Must pay liquidated damages to the owner for the overlapping period
  4. Receives neither a time extension nor delay damages

Explanation

When delays are truly concurrent, the owner generally cannot assess liquidated damages for that period because the owner also caused delay, so the contractor gets a time extension. Delay damages are usually denied, however, because the contractor cannot show the owner's delay alone caused the loss.

Question 47Business and Project Management

The 'measured mile' technique is used in a productivity claim to:

  1. Compare unit production rates in an undisrupted period with rates during the disrupted period to derive the loss Correct answer.
  2. Total all project costs and subtract the original bid to find the claim amount
  3. Use the critical path to allocate float among the affected trades
  4. Apply the contract's liquidated damage rate to each day of lost production

Explanation

The measured mile identifies a period of the same work performed without disruption as a benchmark and compares its unit rates with those achieved during the disrupted period. The difference in hours per unit quantifies lost efficiency without relying on total job costs.

Question 48Business and Project Management

The 'total cost' method of proving a construction claim is generally disfavored because it:

  1. Is permitted only when the claim exceeds the remaining contract balance
  2. Cannot be used on projects with a fixed completion date
  3. Requires the contractor to prove the owner intended to cause delay
  4. Assumes the bid and the contractor's performance were flawless and that the owner caused all of the extra cost Correct answer.

Explanation

The total cost method subtracts the bid from the actual cost and attributes the entire difference to the owner, which assumes no estimating error, no contractor inefficiency, and no other cause. Because those assumptions are rarely valid, tribunals prefer methods that isolate the specific cost of the compensable event.

Question 49Business and Project Management

Budget at completion is $500,000 and the cost performance index is 0.80. Using estimate at completion equal to budget at completion divided by the cost performance index, the forecast final cost is:

  1. $625,000 Correct answer.
  2. $400,000
  3. $580,000
  4. $500,000

Explanation

Dividing $500,000 by 0.80 gives $625,000, meaning the project is forecast to finish $125,000 over budget if current cost efficiency continues. The forecast assumes the observed cost performance will persist for the remaining work.

Question 50Business and Project Management

A contract clause that bars the contractor from recovering delay damages from the owner is generally:

  1. Enforceable in all cases, including deliberate owner interference with the work
  2. Enforceable, but typically not applied to delays outside the parties' contemplation, such as owner bad faith or active interference Correct answer.
  3. Applicable only to delays caused by subcontractors
  4. Void in every situation because it limits liability for negligent acts

Explanation

No-damages-for-delay clauses are commonly enforced to bar money recovery for excusable delays, leaving time as the only remedy. Courts usually carve out exceptions for delays not contemplated by the parties, such as owner bad faith, active interference, or abandonment of the contract.